This website is
 sponsored.gif

banner.gif

 Welcome    Main    Forum    FAQ    Useful Links    Sample Letters   Tribunal  

SRI DAMANSARA SDN BHD V. LIM AHAT KIAT @ LIM PEI TIAM

HIGH COURT [KUALA LUMPUR]

ABDUL KADIR MUSA, J

[RAYUAN SIVIL NO: R3-11-130-94]

27 MARCH 1997

[2] GROUNDS OF DECISION

This 15 an appeal by Sri Damansara Sdn. Bhd., the Appellant / Defendant ( 11 the Appellant" ) against the whole decision of the Learned Magistrate dated ll/10/l994 ordering the Appellant to pay the Plaintiff/Respondent, Lim Ahat Kiat @ Lim pei Tiam ( "the Respondent" ), a sum of RM 15,855.15 together with the normal interest and costs ( page 1, Enclosure (7), and page 20,Enclosure (4)). The said sum was awarded for late delivery arising from the Sale and Purchase Agreement dated 13/4/1990 ("S & P") between the parties (pp. 24-60,ibid.). There were 11 grounds of appeal, ("the Memo"; Enclosure (2) ).

However, notwithstanding those 11 grounds, both parties at the inception of the hearing of this appeal agreed that, there Is only one Issue to be considered by the Court. That Issue is, "what constitutes delivery of vacant possession " in respect of a factory. In that context, both parties further agreed that, if vacant possession Is without electricity and water supply, then the Respondent has no case and the court below should not award any damages at all to him, otherwise, he has lawful claim against the Appellant ( page 5, note of evidence "N / E" ) it is to be noted that, there was no dispute that there was a late delivery of vacant possession of the said factory. That being the consensus of the parties, the question that needs further deliberation by the court is, on the facts of this case, what should be the cut-off point for purposes of calculating the reasonable amount of damages that should and justifiably be awarded to the Respondent as a result of the Appellant's breach. For that purpose, clauses 7 and 15 of the S&P are most relevant. The former, which deals with "Construction of infrastructure" was invoked by Y.Bhg. Dato' Abdullah Ngah, learned counsel for the Respondent, while the latter was heavily relied upon by Encik Pradhan, learned counsel for the Appellant. Clause 15 deals with " Delivery of Vacant Possession ". I will next endeavour to examine both the said Clauses in greater depth.

Clause 15.1. of the S&P provides:
15.1. subject to any extension or extensions of time as may be allowed by the Architect and provided that the Purchaser shall have paid to the vendor all instalments of the purchase price and any other sums under this Agreement as and when due and payable, the said property, without any alterations and I or additions to the said Building, shall be completed and be ready for delivery within twenty-four ( 24 )months from the date hereof. in the event that the Vendor shall delay completion of the said Building and the delivery of vacant possession of the said Property to the purchaser beyond the aforesaid period the Vendor shall pay to the Purchaser agreed damages calculated from day to day at the rate of ten Percentum ( l0% ) per annum on the purchase price of the said property from such aforesaid date to the date of actual or deemed delivery of vacant possession of the said property to the Purchaser as hereinafter provided.".(Emphasis, underlined ).

Thus from clause 15.1 of the S&P, it is required of the Appellant to complete and delivery vacant possession of the 3 relevant units of the factory within 24 months from the date of signing the said S&P dated 13/4/l990. Hence, unless such period was extended by the Vendor's Architect, the relevant premises must be completed and vacant possession delivered by the Vendor to the Purchaser on or before 12/4/1992, provided the Purchaser fulfilled all his obligations required of him by Clause 15.1. if those conditions were fulfilled by the Purchaser, but yet the Vendor did not or could not deliver vacant possession to him, then the former will be entitled to claim the agreed damages at the rate of 10% per annum calculated on a daily basis from the date of such failure till actual or deemed delivery took place. What constitutes "actual or deemed delivery of vacant possession" Is provided by Clause 15.2 of the S&P.

Clause 15.2 aforesaid provides:
15.2 Upon the issuance by the Vendor's Architect of a Certificate certifying that the construction of the said Building has been practically completed in accordance thereof and provided the Purchaser shall have observed and performed the terms and covenants on his part herein contained to be observed the Vendor shall let the Purchaser into possession of the said property PROVIDED THAT such possession shall not give the Purchaser the right to occupy the said Property until such time as the Certificate of Fitness for Occupation is issued by the Appropriate Authorities. Upon the expiry of fourteen (14) days from date of a notice in writing from the Vendor informing the Purchaser to take delivery of the said Property (notwithstanding that the Purchaser may not in fact have taken possession or occupation of the said Property ) the Purchaser shall be deemed to have taken vacant possession of the said Property and I or to the fixtures and fittings thereon".

Thus by the aforesaid Clause 15.2, it was argued by Encik Pradhan that, upon the issuance a certificate by the Vendor's ( Appellant's ) Architect certifying that the construction of the factory has been practically completed in accordance with terms of the S&P ,and the Purchaser ( Respondent ) has fulfilled all his obligations thereunder, it would be incumbent upon the Appellant to let the Respondent into possession of the factory. it was further argued by him, that upon the expiry of fourteen (14) days from the date of the Appellant giving such notice in writing to the Respondent, informing him to take delivery of the said factory, the Respondent shall be deemed to have taken possession of the same irrespective of whether or not, in fact, he has actually took physical possession of the said factory. As such, it was argued that, as from that day onward, the Appellant should be exonerated from any liability for any loss or damage flowing therefrom. On that basis, it was thus contended by Mr Pradhan that, on the facts of this case, delivery of vacant possession took effect 14 days after 09.05.l992; that Is, as from 23. 05. 1992.

However, it is also provided by the said Clause 15.2 that, such possession does not give the Respondent the right to occupy the said factory until the Certificate of Fitness for Occupation is issued by the Appropriate Authorities. What surfaces from that are the issues of

(i) delivery of vacant possession, and
(ii) right to occupy the said factory. Of the two, i can safely infer that (ii) above Is not a contentious issue and need no further deliberation by me. The focal point of the submissions by both the learned counsels is the issue of "delivery of vacant possession". Any delay in doing so by the Appellant, entitled the Respondent to claims agreed damages for every day of such  delay at the rate of l0% per annum on the purchase price of the said factory. On the facts of this case, it was hi5 contention that, vacant possession took effect 14 day after 0.05.1992 as evidenced by the Appellant's letters exhibited at pages 61 - 64 of Enclosure (4). That date 15. 23.05.1992 ; thereafter, the Respondent will be entitled to claim agreed damages as mentioned earlier.

According to Encik Pradhan those 3 letters amounted to " notice in writing " by the Appellant to the Respondent informing him to take delivery of vacant possession of the said factory as contemplated by Clause 15.2 of the S&P. Those letters were accompanied with the necessary certificates issued by the Appellant's Architect " ... certifying that the construction of the said factory has been practically completed ... " as required by Clause 15.2 of the same. Thus it follows that the damages entitlement available to the Respondent should only be limited to 23.05.1992, which 15, 14 days after the 09.05.1992 letters referred to earliar.

The basis of his contention was platformed on the pleadings of the Respondent itself which was based on the terms of the S&P, and not the time when the Respondent was actually being supplied with water and electricity supplies as concluded by the Learned Magistrate ( i.e. 11.11.1992; page 19, NIE ). He argued that, it was wrong for the Learned Magistrate to have applied housing laws to any sale and purchase agreement involving factory premises as in this case. He therefore submitted that, her reliance on the cases of Syarikat Lean Hup ( Liew Brothers ) Sdn. Bhd. v Cheow Chong Thai 1998 J 3 MCJ 221, and Charles Muriel (f) v Newacres Sdn Bhd ( 1994 J 2 AMR) 1145, was certainly a misapplication of an appropriate law. Instead, he contended that the nearest case that can be relied on and could have been applicable to the factual situation of this appeal is the case of Salmah binti Sulaiman & Anor. v Metroplex Development Sdn. Bhd. (1994 J 2 AMR 47, 2514 where it was held that, the developer's obligation under the relevant sale and purchase agreement includes the connection of electricity and water mains outside to the internal electricity and water mains and not the flow of water and electricity as contended by the learned counsel for the Respondent.

Yang Bahagia Dato' Abdullah on the other hand strongly contended that, one of the Appellant's obligations under the S&P is to supply water and electricity under Clause 7.1 of the same since the said Clause 15 certainly part and parcel of the S & P Clause 7.1 which deals with " Construction of Infrastructure"stipulates:

"7.1 The Vendor shall at its own cost and expense construct or cause to be constructed ... water main ... The Vendor shall also at its own cost and expense provide for the supply of water, ... and facilities for the supply of electrical power sufficient for normal lighting only to the switchbox of the said Building PROVIDED HOWEVER that the Purchaser shall be liable for and pay all deposits and turning on fees for the supply of electricity and water to the said ] Building including the cost of the water and electricity meter and internal wiring and other electrical installations."

which requires the Appellant to provide the necessary facilities in respect of water and electricity supplies for normal usage expected of a factory. Failure to do so according to him, one cannot construe that the said factory " has been practically completed " within the intention of Clause 15.1 of the S&P. As such, unless by the Appellant's Architect the 24 months period referred to in the said Clause 15.1, should therefore be calculated from the date of signing the S&P (i.e.13.04.1990 ) till actual delivery of vacant possession ( Cl. 15.1, ibid. ), or such delivery of vacant possession is deemed to take effect by virtue of Clause 15.2 of the S&P. Whichever is applicable, it was strong contention that when such event took place, the said factory must be equipped with the necessary facilities for the supplies of water and electricity. He summarised his submission in that context that a factory without water and electricity is not a factory at all."

On the above note, it was his contention that all the cases referred to and relied on by the Learned Magistrate as guidance to similar factual situation involving factories, should not be held to be wrong. Thus her conclusion that, delivery of vacant possession within the ambit of the S&P effectively took place on the 11.11.1992 ( pp 18 & 19, :enclosure (4) ), and not 14 days after the 09.05.1992 letters as contended by Encik Pradhan, must therefore be held to be right, both in law and in fact. There was no such extension envisaged by Clause 15.1 of the S&P ever been adduced.

To strengthen his argument,Yang Bhg. Dato' Abdullah further canvassed that, there was no certificate of the Appellant's Architect ever been issued at all as required by Clause 15.2 of the S&P. The alleged Architect's Certificates" attached to the letters of 09.05.1992, and exhibited at pages 62 A, 64 A and 66 A of NIE were not the necessary certificates as envisaged by the said Clause. They made no mention as to the completion of the factory, but served only to inform the Respondent that, upon taking delivery of vacant possession, he has to settle the balance of RM 7419.40 with 14 days from O9.05.1992 as required by section 3 of the Second Schedule to the S&P (page 55, NIE). With the greatest of respect to him, I could not agree with such a submission for reasons, inter alia , as stated below.

Firstly, if one is to examine closer to those said documents ( I.e. at pp.62 A, 64 A and 66A, ibid. ), the second paragraph of each one of them clearly states that:

"We hereby certify that the following stages of work i,e. BO 41-1-001 TO BO 41-1-109 (DESiGN 1& 2) which make it Possible for delivery of vacant possession to take place have been completed as at May "1992" (The underlined in square bracket added ).

At the bottom of the same, it was signed by Foong Yee Tuck of the " FT AKiTEK". There was no dispute that " FT AKITEK" was the Appellant's Architect for purposes of Clause 15.2 of the S&P. Thus from that, it is without doubt in my mind that, those documents are the Certificates of the Appellant's Architect certifying that the said factory was ready for purposes of the "delivery of vacant possession" as on the 04.05.1992, since all work up to that stage "have been completed" on that date.

However, by section 3 of the Second Schedule to the S&P, upon such delivery, it is required of the Respondent to pay RM 7419.40 for each unit bought by him in the manner stipulated in Clause 3.3 of the S&P ( page 28, N/E). According to the said Clause 3.3, that amount must be paid by the Respondent to the Appellant within 14 days from the date of the notice in writing from the Appellant to pay. That request or demand was made on 0.05.l992 as evidenced in paragraph (4) of each of those 3 letters.

Secondly, the 7th paragraph of all those 3 letters state, inter alia, the following:

"Pursuant to Clause 18 of the [S&P] the developer's defective liability period is for six (6) months after the date of delivery of vacant possession of the buildings."

That "defective liability period" Is in consonant with Clause 18.1 of the S&P (page 41,NIE) and is required by the said Clause in connection with the "delivery of vacant possession" or "deemed delivery" of the same referred to in Clause 15.2 of the S&P.

On the premises above, I therefore held that, those 3 letters dated 09.05.l992 are letters giving the required notice to the Respondent to take delivery of vacant possession in accordance with Clause 15 of the S&P, and not as contended by Yang Bhg. Dato' Abdullah. I also held that, the documents attached to those letters as exhibited at pages 62 A and 66 A of the N/W, are, in  fact, the necessary "Architect's Certificates" referred to by Clause 15.2 of the S&P for the purposes of "delivery of vacant possession " discussed earlier.

In the case of Insun Development Sdn. Bhd. v Azali bin Bakar ( Rayuan Sibil No: 02-348-l994 ) decided on ll.05.1996, the Federal Court, on the l1.05.1996, discussed at length the effect of Clause 17 in relation to a written contract dated and executed on l8.03.1974 for a purchase of a shophouse to be constructed by a licensed housing developer in the case of Loh Wai Lian v S.E.A. Housing Sdn. Bhd. ( 1987 ) 2 MLJ 1. The said Clause 17, in essence, is identical to Clause 15 of the S&P in the present case.

From my close analysis of both Clause 17 in the Loh's case, supra. and Clause 15 of the S&P in this appeal, reveals that they both provide a formula for computation of the agreed liquidated damages which defined not only its terminus a quo ( its opening date) but also its terminus ad quem ( its closing date). in both instances, the premises involved were not residential premises which are normally governed by the Housing Developers ( Control And Licensing ) Act, 1966 ("the 1966 Act" ), but nevetheless the 1966 Act was the law applicable in the aforesaid Loh's case. Thus by Implication and analogy, Ii therefore conclude that, in the present appeal the same law would equally be applicable, in the absence of specific words to the contrary, based on their similarities, both in form and in effect, of those two Clauses.

In the case of the aforesaid Loh's case, Lord Oliver of Aylmerton ( delivering the Judgment of the Board ), at page 3 ( para (D),rt.), said as follows:

"It is, of course beyond doubt that the failure to complete the building on the stipulated date was a breach of contract, but ... [ the ] determinative [ factor of calculating the damages under the contract Agreement ] ... imposed on the developer the obligation to indemnify the purchaser for any delay in delivery of possession ..."

At page 4 (para (c), left), of that case, their Lordships further said:

"The Clause has to be reasonably and sensibly construed. The obligation is introduced by the words 'the vendor shall ' and there follows the calculation of the sum which he is to pay carefully defined by its opening and closing date." (Emphasis, underlined ).

In Clause 15.1 of the S&P, the words " ... the Vendor shall pay " to the Purchaser incorporated thereto, was also followed by a well defined calculation as that found in the aforesaid Loh's case. As such, my conclusion is that, the same principle would apply to the present appeal. in that respect, I would not be out of place to quote section 38 (1) of the Contract Act,1950, which states as follows:

 "38. Obligation of parties to contracts.
(1) The parties to a contract must... perform ... their respective promises, unless the performance is dispensed with or excused under this Act, or of any other law."

The word "obligation" is found in all the instances quoted above. The performance of that ''obligation'' referred to can only be exonerated if it is depensed with or excused under[ the Contract Act l950 (" the 1950 Act")], or of any other law." such as the 1966 Act. Viewing the S&P microscopically, i failed to find such dispensation or excuse . instead, the S&P imposes the Appellant to provide:

(i) the facilities to the supply of water, and
(ii) the facilities for the supply of electrical power sufficient for normal lighting only to the switchbox of the said building,

under Clause 7.1 of the same.

Clause 7.1 speaks of providing the "facilities" for the supplies of water and electricity, but certainly not the actual supplies of the same which are not within the control of the Appellant. in that context, I share and subscribe fully to the decision of Siti Norma, J.as she then was ) in the case of Salmah Bt. Sulaiman & Anor v Metroplex Development Sdn. Bhd. ( 1994 ) (3) A.M.R. 47, 2514 in the aforesaid Salmah's case, at page 2515, Her Lordship held that,

"Clause 18 of the sale and purchase agreement exempts the respondent from liability for late delivery where delay is caused by the relevant authorities in supplying water and electricity... ,the respondent's obligation is only to connect the outside electricity and water mains to the internal electricity water mains and not to the flow of water and electricity.
... .
The delay in getting water and electricity supply is due to the relevant authorities, for which the respondent cannot be faulted and for which they had been exempted by Clause 18 of the agreement."(Emphasis, underlined ).

Upon close scrutiny of Her Lordship's judgement at page 2156 of the aforesaid Salmah's case, there is no doubt in my mind that Clause 18 of the said case, in all material particulars, is identical to Clause 15.1 of the S&P. Thus on that score, I conclude that, the Appellant is therefore liable to pay to the Respondent the agreed liquidated damages for late delivery calculated up to the date when both the water and electricity mains were actually installed to the Respondent's factory, and not to the date when the said factory was being actually supplied with the flow of water and electricity. To hold otherwise, would be most unfair to the Appellant, and Is certainly, in my humble view, contrary to the very core intention of Clause 7.1 of the S&P.

Having said that, I also note that, in the said Salmah's case, it can be inferred that, there was no evidence to show that the Vendor had unreasonably delayed in applying to the relevant Authorities to have both the water and electricity mains installed to the premises in question; thus Her Lordship's decision as quoted earlier. Likewise, in the present appeal, the same picture is painted upon close scrutiny to Enclosure (4) and all relevant facts of the case. To do otherwise, in the absence of any cogent evidence to that effect, would amount to pure speculation on my part.

However, in the present appeal, the " Notice dated 09.05.1992 enclosing the relevant " Architect's Certificates " ( page 61 - 66, Enclosure (4) ) made no mention that the water main and or electricity main have been installed or has been applied by the Appellant to have them installed to the said factory. The only piece of useful evidence available is at page 67 of Enclosure (4), whereby the Respondent was informed that both the water and electricity meters have been installed. That letter is dated 11.11.1992, and that was the date the Learned Magistrate, at page 18, ibid., treated it as terminus ad quem for purpose of calculating the liquidated damages in line with the Loh's and the Salmah's cases, supra.

On the premises of the above discussion, and (i) in the absence of any evidence to show or suggest that, there was any unreasonable delay on the part of the Appellant to apply, and for the relevant Authorities to supply, the necessary mains, (ii) the silence about the same in the necessary " Notice " to the Respondent to take delivery of vacant possession and (iii) no evidence has been adduced to show when the Respondent actually received the letter dated 11.11.1992, i conclude that, only Clause 15.1 applies in the present appeal insofar as delivery of vacant possession is concerned. Thus, there is no justifiable reason for me to disturb the findings of the Learned Magistrate as to when vacant possession really took place. That being the only issue both parties agreed required me to determine, I therefore dismiss this appeal with costs. The decision of the Court below 15 hereby upheld.

(DATO' ABDUL KADIR BIN MUSA)

Hakim Mahkamah Tinggi,

Johor Bahru

Johor

27.03.1997

[Appeal dismissed with costs ]

 

 

Main   Forum  FAQ  Useful Links  Sample Letters  Tribunal  

National House Buyers Association (HBA)

No, 31, Level 3, Jalan Barat, Off Jalan Imbi, 55100, Kuala Lumpur, Malaysia
Tel: 03-21422225 | 012-3345 676 Fax: 03-22601803 Email: info@hba.org.my

© 2001-2009, National House Buyers Association of Malaysia. All Rights Reserved.